Loading...
HomeMy WebLinkAboutAGENDA REPORT 2002 1016 CC REG ITEM 10GITEM 1 O • C`TTv orNmoRr kRT., CAT,iroRNTA (iiiy C'nnncil Meeting _ a IC1: �y►rnxl �c� lid -17 ACTTON: MOORPARK CITY COUNCIL AGENDA REPORT TO: The Honorable City Council 45 FROM: Barry K. Hogan, Community Development Director Prepared by Laura Stringer, Senior Management Analyst DATE: October 1, 2002 (CC Meeting of 10/16/02) SUBJECT: Consider Report of Annual Development Agreement Review, Established in Connection with Residential Planned Development Permit No. 97 -1, a 312 -unit Apartment Project Located on the West side of Moorpark Avenue, South of Park Crest Lane and North of the Arroyo Simi (Archstone Communities). BACKGROUND Government Code Section 65864 and City of Moorpark Municipal Code Section 15.40 provides for development agreements between the City and property owners in connection with proposed plans of development for specific properties. Development Agreements are designed to strengthen the planning process, to provide developers some certainty in the development process and to assure development in accordance with the terms and conditions of the agreement. On June 23, 1999 the Moorpark City Council adopted Ordinance No. 259 (effective July 23, 1999), approving a Development Agreement between the City of Moorpark and Jocelyne Abrar (Archstone Communities). The agreement, recorded August 27, 1999 as Document No. 99- 162774, was approved in connection with Residential Planned Development 97 -1, a 312 -unit apartment project (with affordable housing units) on 19.2 acres located generally north of the Arroyo Simi and west of Moorpark Avenue. The agreement remains in full force and effect for five (5) years from the operative date of the agreement (until July 23, 2004), or until one (1) year after the occupancy of the Three Hundred Twelfth (312th) apartment unit, whichever occurs later. Provisions of the agreement require an annual review and report to the City Council on the status of completion of all aspects of the Honorable City Council October 16, 2002 Page 2 agreement. On July 18, 2001, the City Council accepted the Community Development Director's report and recommendation that on the basis of substantial evidence, Archstone Communities had complied in good faith with the terms and conditions of the agreement, and deemed the annual review process complete for 2001. The developer has submitted the necessary application form, related materials, and fee /deposit for the 2002 annual review. The Community Development Director has reviewed the submitted information, including the project status and provides the following report. DISCUSSION Protect Status Archstone Communities, the developer, has completed the following aspects of Residential Planned Development (RPD) 97 -1: • Project construction is complete and all units have been released for occupancy. • An Affordable Housing Agreement was approved by the City Council on December 19, 2001, and has been implemented. Developer Compliance with Terms of Agreement Archstone Communities' development responsibilities are included in Section 6 of the Development Agreement, and include twelve (12) specific requirements, as summarized below. Compliance with the terms and conditions of the Development Agreement will occur at various stages of the development process. Where no comment appears concerning the Development Agreement Sections identified below, no specific activity has occurred. # REQUIREMENT STATUS 1. Compliance with Development Project construction has Agreement, Project Approvals and been completed. Subsequent approvals. 2. Dedicated lands to be free and The developer has provided clear of liens and encumbrances, clear title to any including off -site property property required for required for street extensions dedications. or improvements, and the property for expansion of Arroyo Simi. S: \Community Development \D A \1997 -01 \Staff Reports \cc 020116.doc 1 w Honorable City Council October 16, 2002 Page 3 # REQUIREMENT STATUS 3. Community Services Fee at $2,845 Paid for 312 units per unit. ($887,640) on August 17, 2000. 4. Park Fee at $3,000 per unit. Paid for 312 units ($936,000) on August 17, 2000. S. Development Fee at $2,500 per Paid for 312 units unit. ($780,000) on August 17, 2000. 6. Citywide Traffic Fee at $3,000 Paid for 312 units per unit. ($936,000) on August 17, 2000. 7. Payment of all outstanding city The project processing processing and environmental account balance is processing costs. current, and the $1,760 deposit for Development Agreement - Annual Review, was paid on September 18, 2002 8. Waiver of rights to any density No additional density bonus beyond 312 units approved bonus has been requested for this project or granted. 9. Agreement to cast affirmative vote for the formation of an assessment district with the power to levy assessments for the maintenance of parkway landscaping, street lighting (upon Council request - parks conferring special benefits). 10. Guarantee Affordability of An affordable Housing sixty -two (62) units: Agreement was approved by Thirty -seven (37) lower income City Council on December (800 or less of Ventura County 12, 2001, and has been median income). implemented Nineteen (19) very low income (50o or less of Ventura County median income). Six (6) very very low income 330 or less of Ventura County median income). S: \Community Development \D A \1997 -01 \Staff Reports \cc 020116.doc qty' : Cl Pxe Honorable City Council October 16, 2002 Page 4 # REQUIREMENT STATUS 11. Agreement to pay all City capital All development and improvement, development and capital improvement fees processing fees and agreement not have been paid. to protest fees. 12. Design, pay plan check, Park Lane street administrative and inspection improvements have been costs, post surety, and construct constructed. one -half of the future ultimate 2. width of Park Lane (street Area of Contribution (AOC) improvements) from current Fee ($300,000) was paid terminus south to the August 17, 2000. intersection with new east /west 3. street to be built by the Paid for 312 units developer. ($156,000) on August 17, City Compliance with Terms of Agreement The City's responsibilities are in agreement and include four (4) specif below. Where no comment appears Agreement Sections identified below occurred. cluded in Secti is provisions, concerning the , no specific on 7 of the is summarized Development activity has # REQUIREMENT STATUS 1. Expedite (to the extent Project construction has possible) the processing of plan been completed. checking; excavation, grading, building, encroachment and street improvement permits; certificate of occupancy, utility connection authorizations etc. 2. Agreement that the Los Angeles Area of Contribution (AOC) Avenue Area of Contribution Fee ($300,000) was paid (AOC) Fee for the project shall August 17, 2000. be in the amount of $300,000. 3. Agreement that the Traffic Paid for 312 units System Management Fee (TSM) for ($156,000) on August 17, the project shall be in the 2000. amount of $500 per unit. S: \Community Development \D A \1997 -01 \Staff Reports \cc 020116.doc Honorable City Council October 16, 2002 Page 5 # REQUIREMENT STATUS 4. Agreement to allow certain modifications to the City Zoning Code and development standards, including parking ratios, encroachments into required setbacks, project density, required number of covered parking spaces. Evaluation of Good Faith ComlDliance Based on a review of the Development Agreement Annual Review Application and the status of the project, the Community Development Director has determined, on the basis of substantial evidence that Archstone Communities has, to date, complied in good faith with the terms and conditions of the agreement. STAFF RECOMMENDATION 1. Accept the Community Development Director's Report and recommendation that, on the basis of substantial evidence, Archstone Communities has complied in good faith with the terms and conditions of the agreement. 2. Deem the annual review process complete. Attachments: 1. Location Map 2. Site Plan 3. Letter from Archstone dated September 16, 2002 4. Development Agreement S: \Community Development \D A \1997 -01 \Staff Reports \cc 020116.doc LOCATION MAP CC ATTACHMENT 1 �NAV C'l c N1 SITE"" 300 ,Nl c, NORTW I MAJE''TIC SIV CT lc� 0, �j DR 13, I SWIVERY MEREST �A cc Po C c cr V AV ■ ■ 2 12200 t 100. 09 Eai UNIDOS AV 21': SEE IW E3 'cl, JAP&S < AV AV I PAL0141TAS C►R C) LORETTA AR 1 CC ATTACHMENT 1 �NAV C'l c N1 SITE"" 300 ,Nl c, NORTW I MAJE''TIC SIV CT lc� 0, �j DR 13, i - - - LMfTS-OF WORK - - - PARK CREST LANE - - - ------------------ - - - -- -------------------- - - - - -- , i I Ij I, MCC PREPARED FOR: ARGYSTCNE COMMUNITIES The Keith Companies 277 Technology Drive 2955 Red Hill Avenue, Irvine, California 926'8 Costa Meso, CA 92626 ,(949) 789 -1500 !774) 540 -0800 F f 8 T z "e J II LU W LU -I Y i i MCC PREPARED FOR: ARGYSTCNE COMMUNITIES The Keith Companies 277 Technology Drive 2955 Red Hill Avenue, Irvine, California 926'8 Costa Meso, CA 92626 ,(949) 789 -1500 !774) 540 -0800 F f 8 T z "e A R C H S T 0 N E September 16, 2002 Ms. Laura Stringer Senior Management Analyst City of Moorpark 799 Moorpark Avenue Moorpark, CA 93021 Re: Development Agreement Annual Review Dear Ms. Stringer: Archstone Communities 217 Technology Drive, Second Floor Irvine, California 92618 Telephone (949) 789 1500 www.archstonecommunities.com Pursuant to the Development Agreement by and between the City of Moorpark and Archstone Communities, dated July 19, 1999, below is a current status report on Archstone Moorpark apartments. The construction of Archstone Moorpark apartments, including both onsite and offsite improvements, has been completed. The final certificate of occupancy was issued in May 2002 and the project achieved full stabilization in August 2002. As of the date of this letter, we have submitted as -built plans for review by the City Engineer and are processing a final punch list required to have our improvements accepted by the City of Moorpark. We anticipate that the as -built plans and punch list should be complete by the end of September 2002. I hope the information above, along with the enclosed Annual Review Application form, the application fee and 2 copies of our site plan will be sufficient for your annual review process. Please let me know if you need any additional information. Sincerely, �A 1—oKn Hyde Development Associate Enclosures Copy: John Luedtke (w /o enclosures) CC ATTACHMENT 3 Recording Requested By And When Recorded Return to: CITY CLERK CITY OF MOORPARK 799 Moorpark Avenue Moorpark, California 93021 1 99- 162774 1 Rec Fee .00 1 A. R. .00 Recorded I Official Records I County of I Ventura I Richard D. Dean I Recorder 1 8:02as 27- Aug -99 I MOOR GI 28 DEVELOPMENT AGREEMENT BY AND BETWEEN THE CITY OF MOORPARK AND ARCHSTONE COMMUNITIES THIS AGREEMENT SHALL BE RECORDED WITHIN TEN DAYS OF EXECUTION BY ALL PARTIES HERETO PURSUANT TO THE REQUIREMENTS OF GOVERNMENT CODE §65868.5 CC ATTACHMENT 4 m DEVELOPMENT AGREEMENT This Development Agreement ( "the Agreement ") is made and entered into by and between the CITY OF MOORPARK, a municipal corporation, (referred to hereinafter as "City ") and JOCELYNE ABRAR, a Single Woman (referred to hereinafter as "Developer "). City and Developer are referred to hereinafter individually as "Party" and collectively as "Parties." In consideration of the mutual covenants and agreement's contained in this Agreement, City and Developer agree as follows: 1. Recitals. This Agreement is made with respect to the following facts and for the following purposes, each of which is acknowledged as true and correct by the Parties: 1.1. Pursuant to Government Code section 65864 et sec'. and Moorpark Municipal Code chapter 15.40, City is authorized to enter into a binding contractual agreement with any person having a legal or equitable interest in real property within the City in order to establish certainty in the development process. 1.2. Developer is owner in fee simple of certain real property in the City of Moorpark, consisting of approximately nineteen and two tenths (19.2) acres generally located north of the Arroyo Simi and west of Moorpark Avenue as more specifically described by the legal description set forth in Exhibit A, which exhibit is attached hereto and incorporated herein by this reference (the "Property "). 1.3. City has approved, or is in the process of approving, General Plan Amendment No. 97- 3( 11GP11), Zone Change No. 97 -7 ("ZC"), , and Residential Planned Development Permit No. ("RPD "). Implementation of these land use entitlements is subject to a mitigation monitoring program that was approved by City on June 23, 1999 (the "Mitigation Monitoring Program "). (The GP, ZC, RPD and Mitigation Monitoring Program are collectively referred to as the "Project Approvals ".) The Project Approvals authorize a residential development consisting of 312 apartments on the Property (the "Project "). 1.4. By this Agreement, City desires to obtain the binding agreement of Developer to develop the Property in accordance with the Project Approvals and this Agreement. In consideration thereof, City agrees to limit the future exercise of certain of its governmental and proprietary powers to the extent specified in this Agreement. 2 ARCHSTONE DA.4 C 0,` '• 1.5. By this Agreement, Developer desires to obtain the binding agreement of City to permit the development of the Property in accordance with the Project Approvals and this Agreement. In consideration thereof, Developer agrees to waive its rights to legally challenge the limitations and exactions imposed upon the development of the Property pursuant to the Project Approvals and this Agreement and to provide the public benefits and improvements specified in this Agreement. 1.6. City and Developer acknowledge and agree that the consideration that is to be exchanged pursuant to this Agreement is fair, just and reasonable and that this Agreement is consistent with the General Plan of City as amended by General Plan Amendment No. 97 -1. 1.7. On May 24, 1999, the Planning Commission of City commenced a duly noticed public hearing on this Agreement and at the conclusion of the hearing recommended approval of the Agreement. 1.8. On June 2, 1999, the City Council of City ( "City Council ") commenced a duly noticed public hearing on this Agreement, and at the conclusion of the hearing approved the Agreement by Ordinance No. 259 ( "the Enabling Ordinance "). 2. Property Subject To This Agreement. All of the Property shall be subject to this Agreement. The Property may also be referred to hereinafter as "the site" or "the Project area ". 3. Binding Effect. The burdens of this Agreement are binding upon, and the benefits of the Agreement inure to, each Party and each successive successor in interest thereto and constitute covenants that run with the Property. Whenever the terms "City" and "Developer" are used herein, such terms shall include every successive successor in interest thereto. 3.1. Constructive Notice and Acceptance. Every person who acquires any right, title or interest in or to any portion of the Property in which the Developer has a legal interest is, and shall be, conclusively deemed to have consented and agreed to be bound by this Agreement, whether or not any reference to the Agreement is contained in the instrument by which such person acquired such right, title or interest. 3.2. Release Upon Transfer. Upon the sale or transfer of the Developer's interest in any portion of the Property, that Developer shall be released from its obligations with respect to the portion so sold or transferred subsequent to the effective date of the ARCHSTONE DA.4 sale or transfer, provided that the Developer (i) was not in breach of this Agreement at the time of the sale or transfer and (ii) prior to the sale or transfer, delivers to City a written assumption agreement, duly executed by the purchaser or transferee and notarized by a notary public, whereby the purchaser or transferee expressly assumes the obligations of Developer under this Agreement with respect to the sold or transferred portion of the Property. Failure to provide a written assumption agreement hereunder shall not negate, modify or otherwise affect the liability of the purchaser or transferee pursuant to this Agreement. Nothing contained herein shall be deemed to grant to City discretion to approve or deny any such sale or transfer, except as otherwise expressly provided in this Agreement. 4. Development of the Property. The following provisions shall govern the development and use of the Property. 4.1. Permitted Uses. The permitted and conditionally permitted uses of the Property shall be limited to those that are allowed by the Project Approvals and this Agreement. 4.2. Development Standards. All design and development standards, including but not limited to density or intensity of use and maximum height and size of buildings, that shall be applicable to the Property are set forth in the Project Approvals and this Agreement. 4.3. Building Standards. All construction on the Property shall adhere to the Uniform Building Code, including the Fire Resistive Design Manual, the National Electrical Code, the Uniform Plumbing Code, the Uniform Mechanical Code, the Uniform Housing Code, the Uniform Code for the Abatement of Dangerous Buildings, the Uniform Code for Building Conservation and the Uniform Administrative Code in effect at the time the plan check or permit is approved and to any federal or state building requirements that are then in effect (collectively "the Building Codes "). 4.4. Reservations and Dedications. All reservations and dedications of land for public purposes that are applicable to the Property are set forth in the Project Approvals and this Agreement. 4 ARCHSTONE DA.4 5. Vesting of Development Rights. 5.1. Timing of Development. In Pardee Construction Co. v. City of Camarillo, 37 Cal.3d 465 (1984), the California Supreme Court held that the failure of the parties therein to provide for the timing or rate of development resulted in a later - adopted initiative restricting the rate of development to prevail against the parties' agreement. City and Developer intend to avoid the result in Pardee by acknowledging and providing that Developer shall have the right, without obligation, to develop the Property in such order and at such rate and times as Developer deems appropriate within the exercise of its subjective business judgment. In furtherance of the Parties' intent, as set forth in this section, no future amendment of any existing City ordinance or resolution, or future adoption of any ordinance, resolution or other action, that purports to limit the rate or timing of development over time or alter the sequencing of development phases, whether adopted or imposed by the City Council or through the initiative or referendum process, shall apply to the Property. In particular, but without limiting any of the foregoing, no numerical restriction shall be placed on the number of dwellings units that can be built each year within the Project Area. However, nothing in this section shall be construed to limit City's right to insure that Developer timely provides all infrastructure required by the Project Approvals and this Agreement. 5.2. Amendment of Project Approvals. No amendment of any of the Project Approvals, whether adopted or approved by the City Council or through the initiative or referendum process, shall apply to any portion of the Property, unless the Developer has agreed in writing to the amendment. 5.3. Issuance of Subsequent Approvals. Applications for land use approvals, entitlements and permits, including without limitation subdivision maps, subdivision improvement agreements and other agreements relating to the Project, lot line adjustments, preliminary and final planned development permits, use permits, design review approvals (e.g. site plans, architectural plans and landscaping plans), encroachment permits, and sewer and water connections that are necessary to or desirable for the development of the Project (collectively "the Subsequent Approvals "; individually "a Subsequent Approval ") shall be consistent with the 0 ARCHSTONE DA.4 Project Approvals and this Agreement. For purposes of this Agreement, Subsequent Approvals do not include a final subdivision map or building permits. The term of any Subsequent Approval, except a tentative map, shall be one year; provided that the term may be extended by the decision maker for two (2) additional one (1) year periods upon application of the Developer holding the Subsequent Approval filed with City's Department of Community Development prior to the expiration of that Approval. Each such Subsequent Approval shall be deemed inaugurated, and no extension shall be necessary, if a building permit was issued and the foundation received final inspection by City's Building Inspector prior to the expiration of that Approval. It is understood by City and Developer that certain Subsequent Approvals may not remain valid for the term of this Agreement. Accordingly, throughout the term of this Agreement, the Developer shall have the right, at its election, to apply for a new permit to replace a permit that has expired or is about to expire. Subsequent Approvals shall be governed by the Project Approvals and by the applicable provisions of the Moorpark General Plan, the Moorpark Municipal Code and other City ordinances, resolutions, rules, regulations, policies, standards and requirements as most recently adopted or approved by the City Council or through the initiative or referendum process and in effect at the time that the application for the Subsequent Approval is deemed complete by City (collectively "City Laws "), except City Laws that: (a) change any permitted or conditional permitted uses of the Property from what is allowed by the Project Approvals; (b) limit or reduce the density or intensity of the Project, or any part thereof, or otherwise require any reduction in the square footage or number of proposed buildings or other improvements from what is allowed by the Project Approvals; (c) limit or control the rate, timing, phasing or sequencing of the approval, development or construction of all or any part of the Project in any manner, provided that all infrastructure required by the Project Approvals to serve the 6 ARCHSTONE DA.4 portion of the Property covered by the Subsequent Approval is in place or is scheduled to be in place prior to completion of construction; (d) are not uniformly applied on a City -wide basis to all substantially similar types of development projects or to all properties with similar land use designations; (e) control residential rents; or (f) modifies the land use from what is permitted by the General Plan Land Use Element at the date the Enabling Ordinance is adopted or that prohibits or restricts the establishment or expansion of urban services including but not limited to community sewer systems to the Project. 5.4. Modification Of Approvals. Throughout the term of this Agreement, the Developer shall have the right, at its election and without risk to any right that is vested in it pursuant to this section, to apply to City for minor modifications to Project Approvals and Subsequent Approvals. The approval or conditional approval of any such minor modification shall not require an amendment to this Agreement, provided that, in addition to any other findings that may be required in order to approve or conditionally approve the modification, a finding is made that the modification is consistent with this Agreement. 5.5. Issuance of Building Permits. No building permit, final inspection or certificate of occupancy will be unreasonably withheld from the Developer if all infrastructure required by Project Approvals to serve the portion of the Property covered by the building permit is in place or is scheduled to be in place prior to completion of construction and all of the other relevant provisions of the Project Approvals, Subsequent Approvals and this Agreement have been satisfied. In no event shall building permits be allocated on any annual numerical basis or on any arbitrary allocation basis. 5.6. Moratorium on Development. Nothing in this Agreement shall prevent City, whether by the City Council or through the initiative or referendum process, from adopting or imposing a moratorium on the processing and issuance of Subsequent Approvals and building permits and on the finalizing of building permits by means of a final inspection or certificate of occupancy, provided that the moratorium is adopted or imposed (i) FA ARCHSTONE DA.4 ! t on a City -wide basis to all substantially similar types of development projects and properties with similar land use designations and (ii) as a result of a utility shortage or a reasonably foreseeable utility shortage, including without limitation a shortage of water, sewer treatment capacity, electricity or natural gas. 6. Developer Agreements. 6.1. The Developer shall comply with (i) this Agreement, (ii) the Project Approvals, and (iii) all Subsequent Approvals for which it was the applicant or a successor in interest to the applicant. 6.2. All lands and interests in land dedicated to City shall be free and clear of liens and encumbrances other than easements or restrictions that do not preclude or interfere with use of the land or interest for its intended purpose, as reasonably determined by City. 6.3. As a condition of issuance of a building permit for each residential dwelling unit, Developer shall pay City a community services fee as described herein (Community Services Fee). The Community Services Fee may be expended by City in its sole and unfettered discretion. The amount of the Community Services Fee shall be Two Thousand, Eight Hundred Forty -Five Dollars ($2,845.00) per residential unit. The Community Services Fee shall be adjusted annually (commencing two (2) years after the first residential building permit is issued within the project) by any increase in the Consumer Price Index (CPI) until all fees have been paid. The CPI increase shall be determined by using the information provided by the U.S. Department of Labor, Bureau of Labor Statistics, for all urban consumers within the Los Angeles /Riverside /Orange Co. metropolitan area during the prior year. The calculation shall be made using the month which is four (4) months prior to the month in which the Development Agreement is approved by the City Council (e.g., if approval occurs in-June, then the month of February is used to calculate the increase). 6.4. The fee in lieu of park land dedication (Park Fee) pursuant to the requirements of City Ordinance No. 52 shall be paid prior to the issuance of the building permit for each residential unit. The fee shall be Three Thousand Dollars ($3,000.00) for each residential unit. The Park Fee may be expended by the City in its sole and unfettered discretion. On the effective date of this Agreement, the amount of the Park Fee shall be $3,000 per residential unit. Commencing January 1, ARCHSTONE DA.4 2001, and annually thereafter, the Park Fee shall be increased to reflect the change in the State Highway Bid Price Index for the twelve (12) month period that is reported in the latest issue of the Engineering News Record that is available on December 31 of the preceding year ( "annual indexing "). In the event there is a decrease in the referenced Index for any annual indexing, the Park Fee shall remain at its then current amount until such time as the next subsequent annual indexing which results in an increase. 6.5. As a condition of the issuance of a building permit for each residential unit, Developer shall pay City a development fee as described herein (the "Development Fee"). The Development Fee may be expended by City in its sole and unfettered discretion. On the operative date of this Agreement, the amount of the Development Fee shall be two thousand five hundred dollars ($2,500.00). The fee shall be adjusted annually (commencing one (1) year after the first residential building permit is issued within the Project) by any increase in the Consumer Price Index (CPI) until all fees have been paid. The CPI increase shall be determined by using the information provided by the U.S. Department of Labor, Bureau of Labor Statistics, for all urban consumers within the Los Angeles /Riverside /Orange Co. metropolitan area during the prior year. The calculation shall be made using -the month which is four (4) months prior to the month in which the first residential building permit is issued by the City Council (e.g., if issuance occurs in June, then the month of February is used to calculate the increase). 6.6. As a condition of the issuance of a building permit for each residential unit, Developer shall pay City a traffic mitigation fee as described herein ( "Citywide Traffic Fee "). The Citywide Traffic Fee may be expended by the City in its sole and unfettered discretion. On -the effective date of this Agreement, the amount of the Citywide Traffic Fee shall be $3,000 per residential unit. Commencing January 1, 2001, and annually thereafter, the Citywide Traffic Fee shall be increased to reflect the change in the State Highway Bid Price Index for the twelve (12) month period that is reported in the latest issue of the Engineering News Record that is available on December 31 of the preceding year ( "annual indexing ") . In the event there is a decrease in the referenced Index for any annual 9 ARCHSTONE DA.4 indexing, the Citywide Traffic Fee shall remain at its then current amount until such time as the next subsequent annual indexing which results in an increase. 6.7. On the operative date of this Agreement Developer shall pay all outstanding City processing and environmental processing costs related to the project and preparation of this Agreement. 6.8. Developer hereby waives any right it may have under California Government Code Section 65915 et. Seq., or any successor thereto, or any provision of federal, State, or City laws or regulations for application or use of any density bonus that would increase the number of residential units approved for this project to exceed a total of Three Hundred Twelve (312) dwelling units. 6.9. Developer agrees to cast affirmative ballots for the formation of an assessment district with the power to levy assessments for the maintenance of parkway landscaping, street lighting, and if requested by the City Council, parks conferring special benefits, upon properties within the Project. 6.10 Developer, in consideration for a density bonus obtained through the Project Approvals that is greater than would otherwise be available, agrees to guarantee the affordability of sixty -two (62) rental units for the life of the Project. These sixty -two (62) affordable units shall be rented to eligible tenants as follows in A., B., and C.: A. Thirty -Seven (37) units for Lower Income households (80% or less of Ventura County median income) to be rented for no more than 30% of 80% of the Ventura County median income adjusted for household size appropriate to the unit and no more, less a utility allowance. The utility allowance shall be adjusted annually, commencing in the year 2000, based on the change in the Consumer Price Index (CPI). The CPI increase shall be determined by using the information provided by the U.S. Department of Labor, Bureau of Labor Statistics, for all urban consumers within the Los Angeles /Riverside /Orange Co. metropolitan area during the prior year. The calculation shall be made using the month which is four (4) months prior to the month in which the Development Agreement is approved by the City Council (e.g., if approval occurs in June, 10 ARCHSTONE DA.4 then the month of February is used to calculate the increase) . If there is a decrease in the CPI, the utility allowance shall remain at the same amount until the next annual change in CPI results in an increase. Type of Unit Number of Household Size Utility Units Adjustment Allowance one bedroom, one bath 8 2 persons $42 two bedroom, one bath units 12 3 persons $50 two bedroom, two bath units 12 3 persons $50 three bedroom, two bath units 5 4 persons $63 The above Adjustment for Household Size is intended to provide a single rental rate applicable to eligible tenants for each type of unit and, therefore, is applied regardless of actual household size. The Developer may not charge additional rent based on a larger actual household size. (For example, the maximum monthly rent for a low income household of six renting a three bedroom, two bath unit would be calculated as follows: the Ventura County median income for a household of four x .80 x .30 divided by 12 less the utility allowance, $65,300 x .80 x .30 divided by 12 less $63.00 equals $1,243.001. Rather than calculating household income by using 80% of median income, the household income amount for lower income households shall be the amount published by the United States Department of Housing and Urban Development Household Income Limits for Ventura County (HUD Income Limits) or such successor information in the event the referenced published information is no longer available, but in no event less than seventy -three percent (73 %) nor more than eighty percent (80 %) of median income. If the HUD Income Limits household income amount is less than 73% of median income, it shall be set at 73% of median income, and if it is more than 80% of median income, it shall be set at 80% of median income. 11 ARCHSTONE DA.4 B. Nineteen (19) units for Very Low Income households (50% or less of Ventura County median income) to be rented for no more than 30% of 50% of the Ventura County median income adjusted for household size appropriate to the unit and no more, less a utility allowance. The utility allowance shall be adjusted annually, commencing in the year 2000, based on the change in the Consumer Price Index (CPI) . The CPI increase shall be determined by using the information provided by the U.S. Department of Labor, Bureau of Labor Statistics, for all urban consumers within the Los Angeles /Riverside /Orange Co. metropolitan area during the prior year. The calculation shall be made using the month which is four (4) months prior to the month in which the Development Agreement is approved by the City Council (e.g., if approval occurs in June, then the month of February is used to calculate the increase) . If there is a decrease in the CPI, the utility allowance shall remain at the same amount until the next annual change in CPI results in an increase. Type of Unit Number of Household Size Utility Units Adjustment Allowance two bedroom, one bath 6 3 persons $50 two bedroom, two bath units 9 3 persons $50 three bedroom, two bath units 4 4 persons $63 The above Adjustment for Household Size is intended to provide a single rental rate applicable to eligible tenants for each type of unit and, therefore, is applied regardless of actual household size. The Developer may not charge additional rent based on a larger actual household size. (For example, the maximum rent for a very low income single person renting a two bedroom, one bath unit would be calculated as follows: the Ventura County median income for a household of three x .50 x .30 divided by 12 less the utility allowance, $58,800 x .50 x .30 divided by 12 less $50.00 equals $685.001 12 ARCHSTONE DA.4 4 A-r A4 , 3 C. Six (6) units for Very Very Low Income households (33% or less of Ventura County median income) to be rented for no more than 30% of 33% of the Ventura County median income adjusted for household size appropriate to the unit and no more, less a utility allowance. The utility allowance shall be adjusted annually, commencing in the year 2000, based on the change in the Consumer Price Index (CPI) . The CPI increase shall be determined by using the information provided by the U.S. Department of Labor, Bureau of Labor Statistics, for all urban consumers within the Los Angeles /Riverside /Orange Co. metropolitan area during the prior year. The calculation shall be made using the month which is four (4) months prior to the month in which the Development Agreement is approved by the City Council (e.g., if approval occurs in June, then the month of February is used to calculate the increase) . If there is a decrease in the CPI, the utility allowance shall remain at the same amount until the next annual change in CPI results in an increase. Type of Unit Number of Household Size Utility Units Adjustment Allowance two bedroom, one bath units 4 3 persons $50 two bedroom, two bath units 1 3 persons $50 three bedroom, two bath units 1 4 persons $63 The above Adjustment intended to provide applicable to eligible unit and, therefore, actual household size. charge additional rent household size. [Fo monthly rent for a household of four ren bath unit would be cal for Household Size is a single rental rate tenants for each type of s applied regardless of The Developer may not based on a larger actual example, the maximum very very low income .ing a two bedroom, two ;ulated as follows: the Ventura County median income for a household of three x .33 x. .30 divided by 12 less the utility allowance, $58,800 x .33 x .30 divided by 12 less $50.00 equals $435.001. 13 ARCHSTONE DA.4 " ..t 3 #-?' 'r., , *.,k aEa The method of selecting eligible tenants, tenant eligibility requirements, the respective roles of the City and the Developer and any other items determined necessary by the City shall be set forth in an Affordable Housing Implementation and Rental Restriction Plan (the "Plan "). The Plan shall restrict the rents of the sixty -two (62) affordable units to the above not -to- exceed amounts and shall be consistent with this Agreement and approved by the City Council in its sole and unfettered discretion prior to the final inspection and occupancy approval for the first residential unit in the Project. The Developer and City shall, prior to the occupancy of the first residential unit for the Project, execute an Affordable Housing Agreement that incorporates the Plan in total and is consistent with this Agreement. Chapter 17.64 of the Moorpark Municipal Code shall not apply to this Project. Developer shall pay the City's direct costs for preparation and review of the Plan and the Affordable Housing Agreement, up to a maximum of five thousand dollars ($5,000). In addition, the Developer shall not convert the Project to for -sale condominiums community apartments, planned development, stock cooperative, or other common interest development without an amendment to the Plan authorizing such conversion which amendment will require the Developer to provide affordable ownership units as determined by the City under the terms of the amendment but in no event less than sixty -two (62) units in the same numbers by income level as provided in A., B., and C., above. 6.11. In addition to fees specifically mentioned in this Agreement, Developer agrees to pay all City capital improvement, development, and processing fees at the rate and amount in effect at the time the fee is required to be paid. Developer further agrees that unless specifically exempted by this Agreement, it is subject to all fees imposed by City at the operative date of this Agreement and such future fees imposed as determined by City in its sole discretion so long as said fee is imposed on similarly situated properties. Developer further agrees to not protest these fees as may be authorized by Section 66000, et. Seq. of the California Government Code or any other applicable state or federal law. 14 ARCHSTONE DA.4 6.12 Developer shall construct Park Lane (Street Improvements) from its current terminus on its east side of approximately one hundred twenty (120) feet south of Los Angeles Avenue to the intersection with the new east /west street between Moorpark Avenue and Park Lane to be constructed as part of this project. The Street Improvements shall include one -half of the future ultimate width and shall include twenty -six (26) feet of pavement plus curb, gutter, and sidewalk consistent with Plate B -3 -C and any necessary transition and intersection improvements with the future east /west street and current improvements on Park Lane. Developer's obligation to construct Street Improvements shall be contingent on City's acquisition of the real property necessary for said Street Improvements at no cost to Developer. City must obtain the necessary real property within twelve (12) months after the first residential building permit is issued for the Project. Upon written notification from City of its acquisition of the real property within the above referenced time period, Developer shall commence design and shall complete construction prior to obtaining occupancy approval for the last residential building in the Project. Final design, plans and specifications including but not limited to whether the Street Improvements will be on the east or west half of Park Lane shall be approved by the City Council at its sole and unfettered discretion. Developer shall also pay City's costs for plan check and inspection plus City's administrative costs. Within sixty (60) days of receipt of City's notice to commence design of the Street Improvements, Developer shall provide a surety in an amount and form acceptable to City at its sole and unfettered discretion to guarantee construction of the Street Improvements within the aforementioned one year time period. 7. City Agreements. 7.1. City shall process in an expedited manner to the extent possible all plan checking, excavation, grading, building, encroachment and street improvement permits, certificates of occupancy, utility connection authorizations, and other ministerial permits or approvals necessary, convenient or appropriate for the grading, excavation, construction, development, improvement, use and occupancy of the Project. 7.2. City agrees that the Developer's payment of the Los Angeles Avenue Area of Contribution (AOC) Fee for the project shall be in the amount of Three Hundred 15 ARCHSTONE DA.4 Thousand Dollars ($300,000.00) payable prior to issuance of the first building permit for the project. 7.3 City agrees that the Developer's payment of the TSM Fee shall be in the amount of $500.00 for each residential dwelling unit payable prior to the issuance of the building permit for each unit. 7.4 City agrees to allow certain modifications to the City Zoning Code and development standards as follows: A. Allow the project to be built with a 2.13:1 parking ratio as compared to the Code requirement of 2.5:1 spaces per dwelling unit with a total of 666 parking spaces required. B. Allow garages along the western and southerly property line to encroach into the five foot setback and be built to the property line. C. Allow the project to be built at a density of 16.2 units per acre. D. Allow the parking spaces along the northern property line to encroach five (5) feet into the required twenty (20) foot setback. E. Allow the project to be built with one (1) covered space per unit and accept carports as fulfillment of this obligation so long as carports along the perimeter property lines are enclosed on three sides. Allow the uncovered parking and project landscaping along the eastern property line (Moorpark Avenue) to encroach five (5) feet into the required twenty (20) foot setback. F. Chapter 17.64 of the Moorpark Municipal Code shall not apply to this Project. 8. Supersession of Agreement by Change of Law. In the event that any state or federal law or regulation enacted after the date the Enabling Ordinance was adopted by the City Council prevents or precludes compliance with any provision of the Agreement, such provision shall be deemed modified or suspended to comply with such state or federal law or regulation, as reasonably determined necessary by City. 9. Demonstration of Good Faith Compliance. In order to ascertain compliance by the Developer with the provisions of this Agreement, the Agreement shall be reviewed annually in 16 ARCHSTONE DA.4 / ,,e f accordance with Moorpark Municipal Code chapter 15.40. of City or any successor thereof then in effect. The failure of City to conduct any such annual review shall not, in any manner, constitute a breach of this Agreement by City, diminish, impede, or abrogate the obligations of the Developer hereunder or render this Agreement invalid or void. 10. Authorized Delays. Performance by any Party of its obligations hereunder, other than payment of fees, shall be excused during any period of "Excusable Delay ", as hereinafter defined, provided that the Party claiming the delay gives notice of the delay to the other Parties as soon as possible after the same has been ascertained. For purposes hereof, Excusable Delay shall mean delay that directly affects, and is beyond the reasonable control of, the Party claiming the delay, including without limitation: (a) act of God; (b) civil commotion; (c) riot; (d) strike, picketing or other labor dispute; (e) shortage of materials or supplies; (e) damage to work in progress by reason of fire, flood, earthquake or other casualty; (f) failure, delay or inability of City to provide adequate levels of public services, facilities or infrastructure to the Property including, by way of example only, the lack of water to serve any portion of the Property due to drought; (g) delay caused by a restriction imposed or mandated by a governmental entity other than City; or (h) litigation brought by a third party attacking the validity of this Agreement, a Project Approval, a Subsequent Approval or any other action necessary for development of the Property. 11. Default Provisions. 11.1. Default by Developer. The Developer shall be deemed to have breached this Agreement if it: (a) practices, or attempts to practice, any fraud or deceit upon City; or (b) willfully violates any order, ruling or decision of any regulatory or judicial body having jurisdiction over the Property or the Project, provided that Developer may contest any such order, ruling or decision by appropriate proceedings conducted in good faith, in which event no breach of this Agreement shall be deemed to have occurred unless and until there is a final adjudication adverse to Developer; or (c) fails to make any payments required under this Agreement; or (d) materially breaches any of the other provisions of the Agreement and the same is not cured within the time set forth in a written notice of violation from City to 17 ARCHSTONE DA.4 Developer, which period of time shall not be less than ten (10) days from the date that the notice is deemed received, provided if Developer cannot reasonably cure the breach within the time set forth in the notice, Developer fails to commence to cure the breach within such time limit and diligently effect such cure thereafter. 11.2. Default by City. City shall be deemed in breach of this Agreement if it: (a) materially breaches any of the provisions of the Agreement and the same is not cured within the time set forth in a written notice of violation from Developer to City, which period shall not be less than ten (10) days from the date the notice is deemed received, provided if City cannot reasonably cure the breach within the time set forth in the notice, City fails to commence to cure the breach within such time limit and diligently effect such cure thereafter. 11.3. Content of Notice of Violation. Every notice of violation shall state with specificity that it is given pursuant to this section of the Agreement, the nature of the alleged breach, and the manner in which the breach may be satisfactorily cured. The notice shall be deemed given on the date that it is personally delivered or on the third day following the day after it is deposited in the United States mail, in accordance with Section 20 hereof. 11.4. Remedies for Breach. The Parties acknowledge that remedies at law, including without limitation money damages, would be inadequate for breach of this Agreement by any Party due to the size, nature and scope of the Project. The Parties also acknowledge that it would not be feasible or possible to restore the Property to its natural condition once implementation of the Agreement has begun. Therefore, the Parties agree that the remedies for breach of the Agreement shall be limited to the remedies expressly set forth in this subsection. The remedies for breach of the Agreement by City shall be injunctive relief and /or specific performance. The remedies for breach of the Agreement by the Developer shall be injunctive relief and /or specific performance. In addition, and notwithstanding any other language of this Agreement, if the breach is of Subsection 6.9 or 6.10 of this Agreement, City shall have the right to withhold the issuance of building 18 ARCHSTONE DA.4 permits from the date that the notice of violation was given pursuant to Subsection 11.3 hereof until the date that the breach is cured as provided in the notice of violation. Nothing in this subsection shall be deemed to preclude City from prosecuting a criminal action against the Developer if it violates any City ordinance or state statute. 12. Mortgage Protection. At the same time that City gives notice to the Developer of a breach, City shall send a copy of the notice to each holder of record of any deed of trust on the portion of the Property in which Developer has a legal interest ( "Financier "), provided that the Financier has given prior written notice of its name and mailing address to City and the notice makes specific reference to this section. The copies shall be sent by United States mail, registered or certified, postage prepaid, return receipt requested, and shall be deemed received upon the third (3rd) day after deposit. Each Financier that has given prior notice to City pursuant to this section shall have the right, at its option and insofar as the rights of City are concerned, to cure any such breach within fifteen (15) days after the receipt of the notice from City. If such breach cannot be cured within such time period, the Financier shall have such additional period as may be reasonably required to cure the same, provided that the Financier gives notice to City of its intention to cure and commences the cure within fifteen (15) days after receipt of the notice from City and thereafter diligently prosecutes the same to completion. City shall not commence legal action against Developer by reason of Developer's breach without allowing the Financier to cure the same as specified herein. Notwithstanding any cure by Financier, this Agreement shall be binding and effective against the Financier if it takes title to the Property, and every owner of the Property, or part thereof, whose title thereto is acquired by foreclosure, trustee sale or otherwise. 13. Estoppel Certificate. At any time and from time to time, any Developer may deliver written notice to City and City may deliver written notice to the Developer requesting that such Party certify in writing that, to the knowledge of the certifying Party, (i) this Agreement is in full force and effect and a binding obligation of the Parties, (ii) this Agreement has not been amended, or if amended, the identity of each amendment, and (iii) the requesting Party is not in breach of this Agreement, or if in breach, a description of each such breach. The Party receiving such a request shall IM ARCHSTONE DA.4 execute and return the certificate within thirty (30) days following receipt of the notice. City acknowledges that a certificate may be relied upon by successors in interest to the Developer who requested the certificate and by holders of record of deeds of trust on the portion of the Property in which that Developer has a legal interest. 14. Administration of Agreement. Any decision by City staff concerning the interpretation and administration of this Agreement and development of the Property in accordance herewith may be appealed by the Developer to the City Council, provided that any such appeal shall be filed with the City Clerk of City within ten (10) days after the Developer receives notice of the staff decision. The City Council shall render its decision to affirm, reverse or modify the staff decision within thirty (30) days after the appeal was filed. The Developer shall not seek judicial review of any staff decision without first having exhausted its remedies pursuant to this section. 15. Amendment or Termination by Mutual Consent. In accordance with the provisions of Chapter 15.40 of the Moorpark Municipal Code or any successor thereof then in effect, this Agreement may be amended or terminated, in whole or in part by mutual consent of City and the Developer. 16. Indemnification. The Developer shall indemnify, defend with counsel approved by City, and hold harmless City and its officers, employees and agents from and against any and all losses, liabilities, fines, penalties, costs, claims, demands, damages, injuries or judgments arising out of, or resulting in any way from, the Developer's performance pursuant to this Agreement. Developer shall indemnify, defend with counsel approved by City, and hold harmless City and its officers, employees and agents from any against any action or proceeding to attack, review, set aside, void or annul this Agreement or any provision thereof, or the Project Approvals, or any Subsequent Approvals. 17. Time of Essence. Time is of the essence for each provision of this Agreement of which time is an element. 18. Operative_ Date. This Agreement shall become operative on the date the Enabling Ordinance becomes effective pursuant to Government Code Section 36937. 19. Term. This Agreement shall remain in full force and effect for a term of five (5) years commencing on its operative date or until one (1) year after occupancy of the Three Hundred 20 ARCHSTONE DA.4 Twelfth (312`') apartment unit, whichever occurs later, unless said term is amended or the Agreement is sooner terminated as otherwise provided herein. Expiration of the term or earlier termination of this Agreement shall not automatically affect any Project Approval or Subsequent Approval that has been granted or any right or obligation arising independently from such Project Approval or Subsequent Approval. Upon expiration of the term or earlier termination of this Agreement, the Parties shall execute any document reasonably requested by any Party to remove this Agreement from the public records as to the Property, and every portion thereof, to the extent permitted by applicable laws. 20. Notices. All notices and other communications given pursuant to this Agreement shall be in writing and shall be deemed received when personally delivered or upon the third (3rd) day after deposit in the United States mail, registered or certified, postage prepaid, return receipt requested, to the Parties at the addresses set forth in Exhibit "B" attached hereto and incorporated herein. Any Party may, from time to time, by written notice to the other, designate a different address which shall be substituted for the one above specified. 21. Entire Agreement. This Agreement contains the entire agreement between the Parties regarding the subject matter hereof, and all prior agreements or understandings, oral or written, are hereby merged herein. This Agreement shall not be amended, except as expressly provided herein. 22. Waiver. No waiver of any provision of this Agreement shall constitute a waiver of any other provision, whether or not similar; nor shall any such waiver constitute a continuing or subsequent waiver of the same provision. No waiver shall be binding, unless-it is executed in writing by a duly authorized representative of the Party against whom enforcement of the waiver is sought. 23. Severability. If any provision of this Agreement is determined by a court of competent jurisdiction to be invalid or unenforceable, the remainder of this Agreement shall be effective to the extent the remaining provisions are not rendered impractical to perform, taking into consideration the purposes of this Agreement. 24. Relationship of the Parties. Each Party acknowledges that, in entering into and performing under this Agreement, it is acting as an independent entity and not as an agent of the 21 ARCHSTONE DA.4 G 41134 other Party in any respect. Nothing contained herein or in any document executed in connection herewith shall be construed as creating the relationship of partners, joint ventures or any other association of any kind or nature between City and Developer, jointly or severally. 25. No Third Party Beneficiaries. This Agreement is made and entered into for the sole benefit of the Parties and their successors in interest. No other person shall have any right of action based upon any provision of this Agreement. 26. Recordation of Agreement and Amendments. This Agreement and any amendment thereof shall be recorded with the County Recorder of the County of Ventura by the City Clerk of City within the period required by Chapter 15.40 of the Moorpark Municipal Code or any successor thereof then in effect. 27. Cooperation Between City and Developers. City and Developer shall execute and deliver to the other all such other and further instruments and documents as may be necessary to carry out the purposes of this Agreement. 28. Rules of Construction. The captions and headings of the various sections and subsections of this Agreement are for convenience of reference only, and they shall not constitute a part of this Agreement for any other purpose or affect interpretation of the Agreement. Should any provision of this Agreement be found to be in conflict with any provision of the Project Approvals or the Subsequent Approvals, the provision of this Agreement shall prevail. 29. Joint Preparation. This Agreement shall be deemed to have been prepared jointly and equally by the Parties, and it shall not be construed against any Party on the ground that the Party prepared the Agreement or caused it to be prepared. 30. Governing Law and Venue. This Agreement is made, entered into, and executed in the County of Ventura, California, and the laws of the State of California shall govern its interpretation and enforcement. Any action, suit or proceeding related to, or arising from, this Agreement shall be filed in the appropriate court having jurisdiction in the County of Ventura. 31. Attorneys' Fees. In the event any action, suit or proceeding is brought for the enforcement or declaration of any right or obligation pursuant to, or as a result of any alleged breach of, this Agreement, the prevailing Party shall be entitled to its reasonable attorneys' fees and litigation expenses and costs, and any judgment, order or decree rendered in such action, suit or proceeding shall include an award thereof. WA ARCHSTONE DA.4 Attorneys' fees under this section shall include attorneys' fees on any appeal and any post - judgment proceedings to enforce the judgment. This provision is separate and several and shall survive the merger of this Agreement into any judgment on this Agreement. 32. Counterparts. This Agreement may be executed in multiple counterparts, each of which shall be deemed an original, but all of which constitute one and the same instrument. MI ARCHSTONE DA.4 IN WITNESS WHEREOF, Jocelyne Abrar and City of Moorpark have executed this Development Agreement on TU,W 1c1 (999 a Jocelyne,Abr r \qe loper 24 A�&q C-eib�& 0-A9CAed' ARCHSTONE DA.4 t, Y MOORPARK 799 Moorpark Avenue Moorpark, California 93021 (805) 529 -6864 STATE OF CALIFORNIA) COUNTY OF VENTURA ) ss. On this 19th day of July in the year 1999, before me Deborah S. Traffenstedt, City Clerk of the City of Moorpark, California, personally appeared Patrick Hunter, personally known to me to be the person who executed this instrument as the Mayor of the City of Moorpark and acknowledged to me that the City executed it. Witness my hand and Official Seal �: paale� S - -T Deborah S. Traffenst6dt City Clerk PATRICK HUNTER CHRISTOPHER EVANS CLINT D. HARPER DEBBIE RODGERS JOHN E. WOZNIAK Mayor Mayor Pro Tam Councilmember Councilmember Councilmember CALIFORNIA ALL - PURPOSE ACKNOWLEDGMENT State of County of l/ �� � County /� 3 a% before me, A, e � LuzolJ !� V 0 ,)L� filM On Da e t A I Name and Tale of Officer (e.g., 'Jane l5oe. Notary Public personally appeared Name(s) of (proved to me on the basis of satisfactory evidence to be the person whose name is /y$@ subscribed to the within instrument and acknowledged to me that tte(she/rhk executed the same in T�s/her /tKlr authorized capacity64), and that by 4"er /t* signature* on the instrument the person(', NAU+l11QiURANA or the entity upon behalf of which the person(ht acted, Cok'm.#JC 24 Z executed the instrument. Notc.y PuV1C — C@rtOmlO > LOS ANGELES COUN1Y Explte] JUL 2'Y WITNESS my hand and official seal. kZ1 Aw-0 A4 Signature of Notary Public OPTIONAL Though the information below is not required by law, it may prove valuable to persons relying on the document and could prevent fraudulent removal and reattachment of this form to another document. Description of Attached Document Title or Type of C Document Date: Signer(s) Other 7 Capacity(ies) Claimed by Signer(s) Signer's Name: 45 A& C Individual Corporate Officer Title(s): ❑ Partner — ❑ Limited ❑ General ❑ Attorney -in -Fact ❑ Trustee ❑ Guardian or Conservator ❑ Other: Signer Is Representing: /N�i� 0� Ll Signer's Name: Individual Corporate Officer Title(s): Partner — ❑ Limited ❑ General Attorney-in-Fact Trustee Guardian or Conservator Other: Signer Is Representing: L O 1994 National Notary Association • 8236 Remmet Ave.. P.O. Box 7184 • Canoga Park, CA 91309-7184 Prod. No. 5907 Reorder. Call Toll -Free 1.800.876.6827 EXHIBIT A LEGAL DESCRIPTION Assessor's Parcel No. 506 -0- 050 -275 25 ARCHSTONE DA.4 EXHIBIT B To City: City of Moorpark 799 Moorpark Avenue Moorpark, CA 93021 Attn. City Manager To Developer: Jocelyne Abrar 29311 Castle Hill Drive Agoura Hills, CA 91301 John Luedtke, Vice President Archstone Communities 217 Technology Drive Irvine, CA 92618 26